The Code of Federal Regulations of the United States of America

Front Cover
U.S. Government Printing Office, 1983 - Administrative law
0 Reviews
The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government.
 

What people are saying - Write a review

We haven't found any reviews in the usual places.

Other editions - View all

Common terms and phrases

Popular passages

Page 582 - If the contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in Article 1, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay. In such event, the...
Page 645 - Invention or discovery" includes any art, machine, manufacture, design, or composition of matter, or any new and useful improvement thereof, or any variety of plant, which is or may be patentable under the patent laws of the United States of America or any foreign country.
Page 450 - Components" means those articles, materials, and supplies which are directly incorporated In the end products; (II) "End products" means those articles, materials, and supplies which are to be acquired under this contract for public use; and (ill) A "domestic source end product...
Page 492 - Government property." Title to Government property shall not be affected by the incorporation or attachment thereof to any property not owned by the Government, nor shall such Government property, or any part thereof, be or become a fixture or lose its identity as personalty by reason of affixation to any realty.
Page 414 - Consequential damages resulting from the seller's breach include (a) any loss resulting from general or particular requirements and needs of which the seller at the time of contracting had reason to know and which could not reasonably be prevented by cover or otherwise; and (b) injury to person or property proximately resulting from any breach of warranty.
Page 645 - To the point of practical application" means to manufacture in the case of a composition or product, to practice in the case of a process, or to operate in the case of a machine and under such conditions as to establish that the invention is being worked and that its benefits are reasonably accessible to the public.
Page 574 - Use his best efforts to sell, in the manner, at the times, to the extent, and at the price or prices directed or authorized by the Contracting Officer, any property of the types referred to in...
Page 582 - ... unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and such subcontractors or suppliers; and (2) The Contractor, within 10 days from the beginning of any such delay (unless the Contracting Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time...
Page 568 - CPR 1-8.1) , as the definition may be amended from time to time, the Contractor may submit to the Contracting Officer a list, certified as to quantity and quality of any or all items of termination inventory not previously disposed of, exclusive of items the disposition of which has been directed or authorized by the Contracting Officer, and may request the Government to remove such items or enter Into a storage agreement covering them. Not later than fifteen...
Page 581 - Contractor shall continue the performance of this contract to the extent not terminated under the provisions of this clause. (c) Except with respect to defaults of subcontractors, the Contractor shall not be liable for any excess costs if the failure to perform the contract arises out of causes beyond the control and without the fault or negligence of the Contractor. Such causes may include, but are not restricted to, acts of God or of the public enemy, acts of the...

Bibliographic information